Analysis Of Non-excusable Delay Factors Influencing Contractors' Performance In Lagos State, Nigeria
Delays are one of the biggest problems faced by construction firms. The objectives of this study are to identify non-excusable delay factors, their effects on project completion and means of minimising these delays. A questionnaire survey was conducted to solicit the causes, effects and methods o...
| Main Authors: | , , , |
|---|---|
| Format: | Article |
| Language: | English |
| Published: |
Penerbit Universiti Sains Malaysia
2013
|
| Subjects: | |
| Online Access: | http://eprints.usm.my/42025/1/art4_jcdc18-1.pdf |
| _version_ | 1797010748761702400 |
|---|---|
| author | Ibironke, Olajide Timothy Oladinrin, Timo Olugbenga Adeniyi, Onaopepo Eboreime, Idowu Victor |
| author_facet | Ibironke, Olajide Timothy Oladinrin, Timo Olugbenga Adeniyi, Onaopepo Eboreime, Idowu Victor |
| author_sort | Ibironke, Olajide Timothy |
| collection | USM |
| description | Delays are one of the biggest problems faced by construction firms. The objectives
of this study are to identify non-excusable delay factors, their effects on project completion
and means of minimising these delays. A questionnaire survey was conducted to solicit the
causes, effects and methods of minimising delays with two groups of respondents:
consultants and contractors. Data were collected and analysed using a weighted mean
method. A total of 57 major factors that cause non-excusable delays were identified from
the reviewed literature and were further classified into eight major groups. The findings of this
study revealed 20 key factors that cause non-excusable delays. The resultant effects of nonexcusable delays are time overrun, cost overrun and disputes, among others. Ensuring
adequate financial sources, engaging competent project managers and making all
necessary resources available are some of the most important means of minimising nonexcusable delays. Since non-excusable delays are specific to contractors, this study
concludes that contractors should review their activities so that construction work will not be
delayed. |
| first_indexed | 2024-03-06T15:24:17Z |
| format | Article |
| id | usm.eprints-42025 |
| institution | Universiti Sains Malaysia |
| language | English |
| last_indexed | 2024-03-06T15:24:17Z |
| publishDate | 2013 |
| publisher | Penerbit Universiti Sains Malaysia |
| record_format | dspace |
| spelling | usm.eprints-420252018-09-24T03:02:51Z http://eprints.usm.my/42025/ Analysis Of Non-excusable Delay Factors Influencing Contractors' Performance In Lagos State, Nigeria Ibironke, Olajide Timothy Oladinrin, Timo Olugbenga Adeniyi, Onaopepo Eboreime, Idowu Victor TH1-9745 Building construction Delays are one of the biggest problems faced by construction firms. The objectives of this study are to identify non-excusable delay factors, their effects on project completion and means of minimising these delays. A questionnaire survey was conducted to solicit the causes, effects and methods of minimising delays with two groups of respondents: consultants and contractors. Data were collected and analysed using a weighted mean method. A total of 57 major factors that cause non-excusable delays were identified from the reviewed literature and were further classified into eight major groups. The findings of this study revealed 20 key factors that cause non-excusable delays. The resultant effects of nonexcusable delays are time overrun, cost overrun and disputes, among others. Ensuring adequate financial sources, engaging competent project managers and making all necessary resources available are some of the most important means of minimising nonexcusable delays. Since non-excusable delays are specific to contractors, this study concludes that contractors should review their activities so that construction work will not be delayed. Penerbit Universiti Sains Malaysia 2013 Article PeerReviewed application/pdf en http://eprints.usm.my/42025/1/art4_jcdc18-1.pdf Ibironke, Olajide Timothy and Oladinrin, Timo Olugbenga and Adeniyi, Onaopepo and Eboreime, Idowu Victor (2013) Analysis Of Non-excusable Delay Factors Influencing Contractors' Performance In Lagos State, Nigeria. Journal of Construction in Developing Countries , 18 (1). pp. 53-72. ISSN 1823-6499 http://web.usm.my/jcdc/vol18_1_2013/art4_jcdc18-1.pdf |
| spellingShingle | TH1-9745 Building construction Ibironke, Olajide Timothy Oladinrin, Timo Olugbenga Adeniyi, Onaopepo Eboreime, Idowu Victor Analysis Of Non-excusable Delay Factors Influencing Contractors' Performance In Lagos State, Nigeria |
| title | Analysis Of Non-excusable Delay Factors Influencing Contractors'
Performance In Lagos State, Nigeria |
| title_full | Analysis Of Non-excusable Delay Factors Influencing Contractors'
Performance In Lagos State, Nigeria |
| title_fullStr | Analysis Of Non-excusable Delay Factors Influencing Contractors'
Performance In Lagos State, Nigeria |
| title_full_unstemmed | Analysis Of Non-excusable Delay Factors Influencing Contractors'
Performance In Lagos State, Nigeria |
| title_short | Analysis Of Non-excusable Delay Factors Influencing Contractors'
Performance In Lagos State, Nigeria |
| title_sort | analysis of non excusable delay factors influencing contractors performance in lagos state nigeria |
| topic | TH1-9745 Building construction |
| url | http://eprints.usm.my/42025/1/art4_jcdc18-1.pdf |
| work_keys_str_mv | AT ibironkeolajidetimothy analysisofnonexcusabledelayfactorsinfluencingcontractorsperformanceinlagosstatenigeria AT oladinrintimoolugbenga analysisofnonexcusabledelayfactorsinfluencingcontractorsperformanceinlagosstatenigeria AT adeniyionaopepo analysisofnonexcusabledelayfactorsinfluencingcontractorsperformanceinlagosstatenigeria AT eboreimeidowuvictor analysisofnonexcusabledelayfactorsinfluencingcontractorsperformanceinlagosstatenigeria |